This document is an excerpt from the EUR-Lex website
Document 62007TJ0070
Judgment of the Court of First Instance (Eighth Chamber) of 12 November 2008. # Cantieri Navali Termoli SpA v Commission of the European Communities. # State aid - Shipbuilding - Operating aid linked to contracts for ships - Application for extension of ship delivery limit under Article 3 of Regulation (EC) No 1540/98 - Causal link between the exceptional event and the delay. # Case T-70/07.
Judgment of the Court of First Instance (Eighth Chamber) of 12 November 2008.
Cantieri Navali Termoli SpA v Commission of the European Communities.
State aid - Shipbuilding - Operating aid linked to contracts for ships - Application for extension of ship delivery limit under Article 3 of Regulation (EC) No 1540/98 - Causal link between the exceptional event and the delay.
Case T-70/07.
Judgment of the Court of First Instance (Eighth Chamber) of 12 November 2008.
Cantieri Navali Termoli SpA v Commission of the European Communities.
State aid - Shipbuilding - Operating aid linked to contracts for ships - Application for extension of ship delivery limit under Article 3 of Regulation (EC) No 1540/98 - Causal link between the exceptional event and the delay.
Case T-70/07.
Thuarascálacha na Cúirte Eorpaí 2008 II-00250*
ECLI identifier: ECLI:EU:T:2008:486
Judgment of the Court of First Instance (Eighth Chamber) of 12 November 2008 – Cantieri Navali Termoli v Commission
(Case T-70/07)
State aid – Shipbuilding – Operating aid linked to contracts for ships – Application for extension of ship delivery limit under Article 3 of Regulation (EC) No 1540/98 – Causal link between the exceptional event and the delay
1. Actions for annulment – Grounds – Lack of or inadequate statement of reasons – Distinguished from manifest error of assessment (Art. 253 EC) (see para. 37)
2. State aid – Not allowed – Exceptions – Shipbuilding aid (Council Regulation No 1540/98, Art. 3(2)) (see paras 53-58)
Re:
ACTION for annulment of Commission Decision 2006/948/EC of 4 July 2006 on State aid which Italy plans to implement for Cantieri Navali Termoli SpA (OJ 2006 L 383, p. 53). |
Operative part:
The Court:
1. |
Dismisses the action; |
2. |
Orders Cantieri Navali Termoli SpA to pay the costs. |