Access to European Union law
<a href="https://eur-lex.europa.eu/content/help/eurlex-content/experimental-features.html" target="_blank">More about the experimental features corner</a>
Choose the experimental features you want to try
EUR-Lex
Access to European Union law

This document is an excerpt from the EUR-Lex website

You are here
Use quotation marks to search for an "exact phrase". Append an asterisk (*) to a search term to find variations of it (transp*, 32019R*). Use a question mark (?) instead of a single character in your search term to find variations of it (ca?e finds case, cane, care).
Search tips
Need more search options? Use the Advanced search

Document 62007TJ0070

    Judgment of the Court of First Instance (Eighth Chamber) of 12 November 2008.
    Cantieri Navali Termoli SpA v Commission of the European Communities.
    State aid - Shipbuilding - Operating aid linked to contracts for ships - Application for extension of ship delivery limit under Article 3 of Regulation (EC) No 1540/98 - Causal link between the exceptional event and the delay.
    Case T-70/07.

    European Court Reports 2008 II-00250*

    ECLI identifier: ECLI:EU:T:2008:486





    Judgment of the Court of First Instance (Eighth Chamber) of 12 November 2008 – Cantieri Navali Termoli v Commission

    (Case T-70/07)

    State aid – Shipbuilding – Operating aid linked to contracts for ships – Application for extension of ship delivery limit under Article 3 of Regulation (EC) No 1540/98 – Causal link between the exceptional event and the delay

    1.                     Actions for annulment – Grounds – Lack of or inadequate statement of reasons – Distinguished from manifest error of assessment (Art. 253 EC) (see para. 37)

    2.                     State aid – Not allowed – Exceptions – Shipbuilding aid (Council Regulation No 1540/98, Art. 3(2)) (see paras 53-58)

    Re:

    ACTION for annulment of Commission Decision 2006/948/EC of 4 July 2006 on State aid which Italy plans to implement for Cantieri Navali Termoli SpA (OJ 2006 L 383, p. 53).

    Operative part:

    The Court:

    1.

    Dismisses the action;

    2.

    Orders Cantieri Navali Termoli SpA to pay the costs.

    Top